(u) All insurance, guarantees, commitments and agreements entered into by the Seller and Buyer in this Agreement or under this Agreement have the end-of-life date. Notwithstanding any investigation conducted before or after the completion date, one party is entitled to rely on the assurances and guarantees of the other party set out in this agreement. The seller is the current owner of [Product Description]. The company (hereafter “the buyer”) wishes to purchase from the seller and the seller wishes to sell these products to the buyer only on the terms and conditions of this agreement, unless this has been agreed by both the buyer and the seller. The seller is excused for delays in the supply and performance of other contractual obligations arising from this contract, resulting from acts or omissions that are not subject to proper control and are not attributable to the seller`s fault or negligence, including, but not limited, to embargoes, blockages, seizures or freezing of assets. , delays or refusals of an export licence or its suspension or revocation. , or other acts of government, fires, floods, bad weather or other acts of God, quarantines, work strikes or lockouts, unrest, riots, insurrection, civil disobedience, war, shortage of equipment or delays in deliveries to the seller by third parties. If the excusable delay circumstances are extended by six months, each party, at its choice, may terminate the order without penalty, liability and without delay or violation of that order. (q) At the reference date, no action or proceeding against the seller is pending or threatened in a court or public authority if an adverse judgment, settlement or injunction would prevent the implementation of this agreement or any of the transactions or events provided for in this agreement or would lead to the revocation of those transactions , the seller forcing the seller to part with one of his assets or properties in the opinion of the buyer`s lawyer, the transactions contemplated in this case would render it unwise. 2. The buyer assures and guarantees that he has verified the assets and accepts these assets in their current condition, with all errors. The seller hereshes and guarantees that he owns the assets subject to the liabilities covered, but expressly refuses any guarantee of the condition or adequacy of those assets. The buyer must pay the seller the sum of [number of dollars” as the purchase price of the above.